2024版中御公館配套幼兒園裝修項目

2024版中御公館配套幼兒園裝修項目ContractfortheRenovationProjectoftheCentralImperialMansionKindergarten合同編號/ContractNumber:_______甲方（業(yè)主方）/HomeownerParty:公司名稱/CompanyName:_______地址/Address:_______法定代表人/LegalRepresentative:_______聯(lián)系電話/ContactNumber:_______郵箱/Email:_______乙方（承包方）/ContractorParty:公司名稱/CompanyName:_______地址/Address:_______法定代表人/LegalRepresentative:_______聯(lián)系電話/ContactNumber:_______郵箱/Email:_______鑒于甲方需要對中御公館配套幼兒園進(jìn)行裝修，乙方具有相應(yīng)資質(zhì)和能力承接此類裝修工程，甲乙雙方本著平等互利、誠實信用的原則，經(jīng)友好協(xié)商，就幼兒園裝修項目合作事宜達(dá)成如下合同：Article1:ProjectDescription1.1TheprojectinvolvestherenovationofthekindergartenlocatedwithintheCentralImperialMansioncomplex.1.2Thescopeoftherenovationincludes,butisnotlimitedto,interiordesign,construction,anddecoration.Article2:ContractPriceandPaymentTerms2.1Thetotalcontractpricefortherenovationprojectis:_______(specifythetotalcontractprice).2.2Thepaymenttermsareasfollows:_______(detailthepaymentscheduleandconditions).Article3:WorkCommencementandCompletion3.1Thecommencementdateoftherenovationworkis:_______(specifythestartdate).3.2Theexpectedcompletiondateoftherenovationworkis:_______(specifytheexpectedenddate).Article4:QualityStandardsandRequirements4.1Therenovationworkmustadheretothefollowingqualitystandards:_______(listtherelevantstandardsandspecifications).4.2Thematerialsusedmustbeenvironmentallyfriendlyandsafeforchildren.Article5:SafetyandEnvironmentalProtection5.1TheContractorshallcomplywithallapplicablesafetyregulationsandenvironmentalprotectionlawsduringtherenovationprocess.Article6:ProjectManagementandSupervision6.1TheContractorshallappointaprojectmanagerresponsiblefortheday-to-daysupervisionoftherenovationwork.6.2TheHomeownerPartyshallhavetherighttoinspecttheworkatanytimeduringtherenovationperiod.Article7:ChangesandVariations7.1Anychangestotherenovationscopeorspecificationsshallbeagreeduponinwritingbybothpartiesandmayresultinadjustmentstothecontractpriceandtimeline.Article8:DelaysandExtensionsofTime8.1TheContractorshallnotifytheHomeownerPartyimmediatelyofanycircumstancesthatmayresultinadelay.8.2TheHomeownerPartymaygrantextensionsoftimeatitssolediscretion.Article9:Warranties9.1TheContractorwarrantsthatallworkperformedunderthiscontractwillbeofsatisfactoryqualityandfreefromdefectsforaperiodof_______(specifythewarrantyperiod).Article10:LiabilityforBreachofContract10.1Intheeventofabreachofcontractbyeitherparty,thebreachingpartyshallbeliableforanylossesordamagesincurredbythenon-breachingparty.Article11:DisputeResolution11.1AnydisputesarisingoutoforinconnectionwiththiscontractshallberesolvedthrougharbitrationinaccordancewiththerulesofthearbitrationinstitutionspecifiedinthisArticle.Article12:ForceMajeure12.1Neitherpartyshallbeliableforanyfailureordelayinperformingitsobligationsduetoforcemajeureevents.Article13:AssignmentandSubcontracting13.1TheContractorshallnotassignorsubcontractitsrightsorobligationsunderthiscontractwithoutthepriorwrittenconsentoftheHomeownerParty.Article14:Notices14.1Allnoticesunderthiscontractshallbeinwritingandshallbedeemedeffectiveuponreceipt.Article15:GoverningLaw15.1ThiscontractshallbegovernedbyandconstruedinaccordancewiththelawsofthejurisdictionspecifiedinthisArticle.Article16:EntireAgreement16.1Thiscontractconstitutestheentireagreementbetweenthepartiesandsupersedesallpriornegotiations,understandings,andagreements.甲方（蓋章）/HomeownerParty(Seal):_______乙方（蓋章）/ContractorParty(Seal):_______法定代表人或授權(quán)代表簽字/LegalRepresentativeorAuthorizedSignatory:_______簽訂日期/DateofSigning:_______（注：以上為合同的前半部分，合同的后半部分將在下一個提問中繼續(xù)提供。）正文結(jié)束即停止回答。Article17:InsuranceandIndemnification17.1TheContractorshallmaintainadequateinsurancecoverageforthedurationoftheproject,includingbutnotlimitedtoconstructionallrisksinsuranceandpublicliabilityinsurance.17.2TheContractorshallindemnifyandholdharmlesstheHomeownerPartyagainstanyclaims,damages,orlossesarisingfromtheContractor'sperformanceofthework.Article18:SiteAccessandConditions18.1TheHomeownerPartyshallprovidetheContractorwithreasonableaccesstothesiteandensurethatthesiteconditionsaresuitableforthecommencementofwork.18.2TheContractorshallberesponsibleformaintainingthesiteinacleanandsafecondition.Article19:IntellectualPropertyRights19.1TheContractorherebyassignstotheHomeownerPartyallintellectualpropertyrightsinanydesigns,plans,andspecificationscreatedfortheproject.Article20:Post-CompletionServices20.1TheContractorshallprovideanynecessarypost-completionservices,includingminoradjustmentsandrectifications,foraperiodof_______(specifytheperiod)afterthecompletionoftheproject.Article21:TerminationforConvenience21.1Eitherpartymayterminatethecontractforconvenienceuponwrittennoticetotheotherparty,subjecttothepaymentofaterminationfeeasspecifiedinthisArticle.Article22:CovenantNottoSue22.1TheContractorcovenantsnottosuetheHomeownerPartyformattersrelatedtotheperformanceofthiscontract,exceptinthecaseofabonafidedispute.Article23:Third-PartyBeneficiary23.1Theprovisionsofthiscontractareintendedtobenefitandbeenforceablebythepartiesandtheirrespectivesuccessorsandassigns.Article24:ExecutionofDocuments24.1Thepartiesshallexecuteanddeliveralldocumentsandinstrumentsnecessarytogivefulleffecttothetermsofthiscontract.Annex1:DetailedRenovationPlanandSpecificationsAnnex2:ListofMaterialsandEquipmentAnnex3:ProjectScheduleandMilestonesAnnex4:InsuranceCertificatesandCoverageDetailsAnnex5:WarrantyandPost-CompletionServicesAgreement一、附件列表/AnnexList:Theannexestothiscontractprovidedetailedrenovationplans,alistofmaterialsandequipment,projectschedules,insurancecertificates,andwarrantyandpost-completionservicesagreementsthatareintegraltotheexecutionofthecontract.二、違約行為及認(rèn)定/BreachofContractandDetermination:Breachofcontractincludes,butisnotlimitedto,failuretomeetdeadlines,non-compliancewithqualitystandards,andfailuretocomplywithsafetyandenvironmentalregulations.Thedeterminationofabreachissubjecttoverificationofthefacts