出口合同模板-2

COMPANYNAMECOMPANYADDRESSTel:0086-25-XXXXXXFax:0086-25-XXXXXXContractSELLER:COMPANYNAMENO.:STREETADDRESS1DATE:STREETADDRESS2L/CNO.:CITY,PROVINCEANDPOSTALCODEDATEOFISSUE:COUNTRYTEL:FAX:BUYER:COMPANYNAMESTREETADDRESS1STREETADDRESS2CITY,PROVINCEANDPOSTALCODECOUNTRYTEL:FAX:茲經(jīng)買(mǎi)賣(mài)雙方同意，本著平等互利，友好合作的原則，由買(mǎi)方購(gòu)進(jìn)，賣(mài)方出售下列貨物，并按下列條款簽訂本合同：ThisCONTRACTismadebyandbetweentheBuyersandtheSellersonthebasisofprinciplesofequalityandmutualbenefit,friendlycooperation;wherebytheBuyersagreetobuyandtheSellersagreetoselltheundermentionedgoodsonthetermsandconditionsstatedbelow:No.ProductNameDimensions(mm)ColorQuantity(set)UnitPrice(USD)Subtotal

(USD)WidthHeightDepth12345TotalFOBNanjing:Sea/AirFreight:Total:SayUSDollarsXXXandXXXCentsOnly裝運(yùn)港：中國(guó)南京目的港PortofLoading:Nanjing,ChinaPortofDestination:運(yùn)輸方式：海運(yùn)/空運(yùn)ShippingMode:bySea/Air運(yùn)輸時(shí)間：賣(mài)方在收到預(yù)付款30天之后發(fā)貨TimeofShipment:TheSellersshalleffecttheshipment30daysafterthereceiptofadvancepayment.時(shí)間改變通知：以上任何一方時(shí)間延期，應(yīng)提前2天書(shū)面通知對(duì)方，如任何一方未履行通知義務(wù)應(yīng)承擔(dān)相應(yīng)責(zé)任。NoticeofChangeofShipmentTime:Ifeitherpartydelays,itshouldinformtheotherpartyofthepostponementinwritingtwodaysinadvance.Theonewhodoesnotfulfillthenotificationobligationshouldundertakethecorrespondingresponsibility.因以下原因造成交貨延誤，交貨期限相應(yīng)順延：a.甲方未能按約定日期支付預(yù)付款、貨款b.甲方未按合同約定提供所需指令、批準(zhǔn)等，致使產(chǎn)品不能正常生產(chǎn)c.產(chǎn)品變更和增加d.不可抗力：本合同規(guī)定的不可抗力e.本合同約定的其他情況Thedeliverywillbepostponedaccordinglyduetothefollowingevents:a.TheBuyersdonotmaketheadvancepaymentandbalanceinduecourse.b.TheBuyersdonotgiverequiredinstructionsorapprovalstipulatedinthecontract,andleadstoabnormalproduction.c.Thechangeandadditionofproducts.d.ForceMajeureprovidedforinthiscontract.e.Othersituationsstipulatedinthiscontract付款條件：TermsofPayment:電匯T/T買(mǎi)方在合同簽訂之后7個(gè)工作日內(nèi)電匯合同總價(jià)款的50%作為預(yù)付款。買(mǎi)方收到賣(mài)方關(guān)于預(yù)計(jì)裝船日期及準(zhǔn)備裝船數(shù)量的通知后，于裝運(yùn)前20天，付清剩下的50%貨款。TheBuyersshallmakethepaymentof50%ofthetotalvalueofcontractasadvancepaymentwithin7daysafterenteringintothecontract.UponreceiptfromtheSellersoftheadviceastothetimeandquantityexpectedreadyforshipment,TheBuyersshallpayupthebalance20daysbeforetheshipment.信用證L/C買(mǎi)方在合同簽訂之后，應(yīng)通過(guò)世界一流的并為賣(mài)方所接受的銀行開(kāi)立以賣(mài)方為受益人的不可撤銷的即期信用證。該信用證可憑即期匯票及其他規(guī)定單據(jù)在開(kāi)證行付款，應(yīng)不遲于2011年12月29日到達(dá)賣(mài)方。TheBuyersshallopenanirrevocablesightLetterofCreditinfavouroftheSellersthroughafirst-classbankacceptabletotheSellers.TheL/CshallbepayablebytheopeningbankagainstsightdraftandshallreachtheSellersbeforeDecember29,2011.溢短裝：數(shù)量上5%的誤差是允許的MoreorLess:atoleranceof5%moreorlessinquantityandamountisallowable.運(yùn)輸嘜頭：由賣(mài)方?jīng)Q定ShippingMark:AtSellers’disposal裝運(yùn)通知：賣(mài)方在貨物裝船后，立即將合同號(hào)、品名、件數(shù)、毛重、凈重、發(fā)票金額、載貨船名及裝船日期以通知買(mǎi)方。AdviceofShipment：TheSellersshalluponcompletionofloading,adviseimmediatelytheBuyersofthecontractnumber,nameofcommodity,numberofpackages,grossandnetweights,invoicevalue,nameofvesselandloadingdate.保險(xiǎn)(CIF成交條件下)：賣(mài)方按CIF發(fā)票價(jià)值110%投保一切險(xiǎn)和戰(zhàn)爭(zhēng)險(xiǎn)Insurance：Tobecoveredbythesellerfor110%ofCIFtotalinvoicevalueagainstallrisksandwarrisk。銀行信息：賬戶名稱:COMPANYNAME銀行名稱:BANKNAME賬號(hào):00000000BankInformation:AccountName:COMPANYNAMEBankName:BANKNAMEAccountNumber:00000000付款延誤、交貨延誤及罰款：付款延誤：買(mǎi)方不按約定支付貨款應(yīng)按銀行3倍同期貸款利率支付延誤付款利息和賠償賣(mài)方由此造成的損失。如果甲方不按約定支付貨款超過(guò)10個(gè)工作日，賣(mài)方有權(quán)解除合同，由此給賣(mài)方造成的損失（包括為實(shí)現(xiàn)該項(xiàng)賠償費(fèi)用而支出的費(fèi)用（包括律師費(fèi)用）由買(mǎi)方賠付。PaymentDelay:ShouldtheBuyersfailtomakethepaymentontime,theBuyersshallpayinterestsofthedelayedpaymentatarateofthreetimescontemporarybanklendingrateandcompensatetheSellersforlossescausedthereof.Ifthedelayisover10workingdays,theSellershaverightstorepudiatethecontract,andthelossestheSellerssufferthereof(includingtherelevantexpensessuchaslawyerfeetoacquiresuchcompensation)shallbemadeupbytheBuyers.供貨延誤：由于賣(mài)方原因造成供貨延誤，延誤超出5天則乙方須向甲方交納罰金。罰金的計(jì)算標(biāo)準(zhǔn)如下：未供貨產(chǎn)品合同金額×0.05%×（逾期交貨天數(shù)-5）,罰金限額為合同價(jià)的5%,處罰金額不足與補(bǔ)償甲方造成的損失,甲方有權(quán)力向乙方追索。如果由于乙方原因造成供貨延誤超過(guò)10個(gè)工作日，甲方有權(quán)解除合同，由此給甲方造成的損失由乙方賠付。ShipmentDelay:ShouldtheshipmentbepostponedbytheSellersandcausesadelayofmorethan5days,theSellersshallpaypenaltyatthefollowingrate:contractvalueofundeliveredgoods×0.05%×（delaydays-5）,theupperlimitofpenaltyis5%ofthetotalvalueofcontract.ProvidedthepenaltyisnotenoughtomakeuptheBuyers’losses,theBuyershaverightstorecourse.Ifthedelayexceeds10workingdays,theBuyershaverightstocancelthecontract,andthelossestotheBuyersshallbecompensatedforbytheSellers.技術(shù)和商業(yè)保密：a.乙方擁有產(chǎn)品的知識(shí)產(chǎn)權(quán)，未經(jīng)乙方許可，甲方所知曉的乙方任何產(chǎn)品的式樣及技術(shù)構(gòu)造、信息、文件、圖紙、信函只能用于執(zhí)行本協(xié)議書(shū)，不得向任何第三方透露，包括但不限于出借、贈(zèng)與、復(fù)印、復(fù)制或者口頭有意無(wú)意地提供給任何第三方或有意無(wú)意地協(xié)助不承擔(dān)保密義務(wù)的任何第三方刺探或得到使用乙方的商業(yè)（或技術(shù)）秘密。b.甲方應(yīng)制定完善的體制確保本協(xié)議所約定的資料或文件只能被制定的甲方為履行合同需要的管理部門(mén)或人員所知曉，如乙方發(fā)現(xiàn)甲方任何有意或無(wú)意地違反本條約定，有權(quán)要求甲方立即采取補(bǔ)救措施和改正。c.雙方應(yīng)對(duì)各自范圍內(nèi)的技術(shù)資料和商務(wù)資料絕對(duì)保密。凡透露給競(jìng)爭(zhēng)對(duì)手商業(yè)機(jī)密且造成利益損失的行為將被訴諸法律。TechnicalandCommercialConfidentialityTheSellersownstheintellectualpropertyrightsofproducts.WithoutSellers’permission,theproductstylesandtechnicalstructures,information,documents,drawingsandlettersknowntotheBuyersareonlyintendedforexecutionofthiscontract,andshouldnotbedisclosedtoanythirdpartyintentionallyorunintentionallybyanymeansincludingbutnotlimitedtolending,giving,reprography,copyororal.ItisalsoforbiddentoassistanythirdpartywhodoesnotassumethedutyofconfidentialitytopryintooracquiretheSellers’commercialortechnicalsecretsintentionallyorunintentionally.TheBuyersshouldestablishaneffectivesystemtoensurethematerialsordocumentsrelativetothiscontractareonlyknowntonecessarymanagementdepartmentandpersonnelinpurposeofcarryingoutthecontract.Ifbreachofthisprovisionoccurs,theSellershaverightstoasktheBuyertotakeremedialmeasuretocorrectfalse.Bothpartiesshouldkeepthetechnicalandcommercialmaterialswithintheirrespectiverangeabsolutelyconfidential.Anybehaviorofdisclosingthetradesecretstocompetitorsandcausinglosseswillleadtolegalaction.產(chǎn)品變更和增加：a.在合同履行過(guò)程中，對(duì)任何變更和增加產(chǎn)品，甲方應(yīng)及時(shí)向乙方下發(fā)書(shū)面指令，沒(méi)有書(shū)面指令乙方可暫緩執(zhí)行，任何變更和增加產(chǎn)品需在費(fèi)用經(jīng)雙方確認(rèn)后方可組織生產(chǎn)。b.乙方確認(rèn)增加和變更的價(jià)款作為追加合同價(jià)款，按照本合同約定的支付方式支付。ChangeandadditionofproductsInthecourseofcontractimplementation,ifthereisanychangeoradditiontoproduct,theBuyersshouldadvisetheSellersinwritingassoonaspossible.Ifwritteninstructionsarenotgiven,theSellerscansuspendoperation.Theproductstobechangedoraddedcanonlybearrangedafterbothpartiesconfirmontheexpenses.Theconfirmationonexpensearisingfromthechangeandadditionofproductswillberegardedasanadditiontothecontract,andshallbesubjecttothepaymenttermsstipulatedinthiscontract.質(zhì)量保證：產(chǎn)品質(zhì)量應(yīng)當(dāng)達(dá)到合同約定的質(zhì)量標(biāo)準(zhǔn)。因賣(mài)方產(chǎn)品質(zhì)量達(dá)不到約定的質(zhì)量標(biāo)準(zhǔn)，由賣(mài)方負(fù)責(zé)提供符合約定質(zhì)量標(biāo)準(zhǔn)的替代品并承擔(dān)由其給買(mǎi)方造成的損失。GuaranteeofQuality：Theproductshouldmeetthequalityrequirementsstipulatedinthiscontract.Shouldtherebedefectiveproduct,theSellershavetheresponsibilitytoprovidereplacementandmakeupforthelosscausedthereof.賣(mài)方對(duì)產(chǎn)品提供質(zhì)量擔(dān)保，擔(dān)保期為一年，從貨物抵達(dá)目的港的那天算起。在擔(dān)保期間，任何由于產(chǎn)品本身的設(shè)計(jì)和制造缺陷而造成的產(chǎn)品質(zhì)量問(wèn)題，賣(mài)方將免費(fèi)提供符合約定質(zhì)量標(biāo)準(zhǔn)的替代品。由于不正當(dāng)安裝、使用等人為因素而造成的問(wèn)題不在擔(dān)保范圍之內(nèi)。Theproductiswarrantedforaperiodof365daysfromthedateofarrivingatportofdestination.Duringthewarrantyperiod,ifthereisanyproblemduetodefectsofproductdesignandfabrication,theSellersshallprovidereplacementfreeofcharge.Theproblemresultedfromhumanfactorsincludingimproperinstallation,unwiseuseandsoforthisbeyondthecoverage.檢驗(yàn)和索賠：貨卸目的口岸，買(mǎi)方有權(quán)申請(qǐng)中華人民共和國(guó)國(guó)家質(zhì)量監(jiān)督檢驗(yàn)檢疫總局進(jìn)行檢驗(yàn)。如發(fā)現(xiàn)貨物的品質(zhì)及/或數(shù)量/重量與合同或發(fā)票不符：除屬于保險(xiǎn)公司及/或船公司的責(zé)任外，買(mǎi)方有權(quán)在貨卸目的口岸后90天內(nèi)，根據(jù)中華人民共和國(guó)國(guó)家質(zhì)量監(jiān)督檢驗(yàn)檢疫總局出具的證明書(shū)向賣(mài)方提出索賠，因索賠所發(fā)生的一切費(fèi)用（包括檢驗(yàn)費(fèi)用）均有賣(mài)方負(fù)擔(dān)。FOB價(jià)格條件時(shí)，如重量短缺，買(mǎi)方有權(quán)同時(shí)索賠短重部分的運(yùn)費(fèi)。InspectionandClaim：TheBuyersshallhavetherighttoapplytotheGeneralAdministrationofQuanlitySupervision,InspectionandQuarantineofthePeople’sRepublicofChina(AQSIQ)forinspectionafterdischargeofthegoodsattheportofdestination.Shouldthequalityand/orquantity/weightbefoundnotinconformitywiththecontractorinvoicetheBuyersshallbeentitledtolodgeclaimswiththeSellersonthebasisofAQSIQ‘sSurveyReport,within90daysafterdischargeofthegoodsattheportofdestination,withtheexception,however,ofthoseclaimsforwhichtheshippingcompanyand/ortheinsurancecompanyaretobeheldresponsible.AllexpensesincurredontheclaimincludingtheinspectionfeeaspertheAQSIQinspectioncertificatearetobebornebytheSellers.IncaseofFOBterms,thebuyersshallalsobeentitledtoclaimfreightforshortweightifany.不可抗力：由于水災(zāi)、火災(zāi)、地震、海嘯、戰(zhàn)爭(zhēng)、罷工等一切無(wú)法預(yù)見(jiàn)、控制和克服的事件導(dǎo)致不能或暫時(shí)不能全部或部分履行本協(xié)議，賣(mài)方不負(fù)責(zé)任。但賣(mài)方必須立即通知買(mǎi)方，并以掛號(hào)函向買(mǎi)方提出有關(guān)政府機(jī)關(guān)或者商會(huì)所出具的證明，以證明事故的存在。由于人力不可抗拒事故致使交貨期限延期一個(gè)月以上時(shí)，買(mǎi)方有權(quán)撤銷合同。賣(mài)方不能取得出口許可證不得作為不可抗力。ForceMajeure：TheSellersshallnotbeheldresponsibleforfailureordelaytoperformalloranypartofthiscontractduetoflood,fire,earthquake,tsunami,war,strikeoranyothereventswhichcouldnotbepredicted,controlledandovercome.However,theSellersshallnotifyimmediatelytheBuyersanddelivertotheBuyersbyregisteredmailacertificateissuedbygovernmentauthoritiesorChamberofCommerceasevidencethereof.IftheshipmentisdelayedoveronemonthastheconsequenceofthesaidForceMajeure,theBuyersshallhavetherighttocancelthisContract.Sellers’inabilityinobtainingexportlicenceshallnotbeconsideredasForceMajeure.仲裁：一切因執(zhí)行本合同或與本合同有關(guān)的爭(zhēng)執(zhí)，應(yīng)由雙方通過(guò)友好方式協(xié)商解決。如經(jīng)協(xié)商不能得到解決時(shí)，應(yīng)提交北京中國(guó)國(guó)際貿(mào)易促進(jìn)委員會(huì)對(duì)外經(jīng)濟(jì)貿(mào)易仲裁委員會(huì)。按照中國(guó)國(guó)際貿(mào)易促進(jìn)委員會(huì)對(duì)外經(jīng)濟(jì)貿(mào)易仲裁委員會(huì)仲裁程序暫行規(guī)定進(jìn)行仲裁。仲裁委員會(huì)的裁決為終局裁決，對(duì)雙方均有約束力。仲裁費(fèi)用除非仲裁委員會(huì)另有決定外，由敗訴一方負(fù)擔(dān)。Arbitration：All