2024版中電建建筑集團(tuán)力薦

2024版中電建建筑集團(tuán)力薦SinohydroConstructionGroupRecommendedContract合同編號(hào)/ContractNumber:_______甲方（委托方）/Client:公司名稱/CompanyName:_______地址/Address:_______法定代表人/LegalRepresentative:_______聯(lián)系電話/ContactNumber:_______郵箱/Email:_______乙方（承包方）/Contractor:公司名稱/CompanyName:_______地址/Address:_______法定代表人/LegalRepresentative:_______聯(lián)系電話/ContactNumber:_______郵箱/Email:_______鑒于甲方需要進(jìn)行建筑施工項(xiàng)目，并選擇乙方作為項(xiàng)目的承包方，甲乙雙方本著平等互利、誠實(shí)信用的原則，經(jīng)友好協(xié)商，就建筑施工項(xiàng)目合作事宜達(dá)成如下合同：Article1:ProjectOverview1.1Theprojecttobeundertakenisdescribedasfollows:_______(provideabriefdescriptionoftheproject).1.2Thelocationoftheprojectis:_______(specifythelocation).Article2:ScopeofWork2.1Thescopeofworkincludesbutisnotlimitedto:_______(listthemainactivitiesandtaskstobeperformedbytheContractor).Article3:ContractPriceandPayment3.1Thetotalcontractpriceis:_______(specifythetotalcontractprice).3.2Thepaymenttermsareasfollows:_______(detailthepaymentscheduleandconditions).Article4:CommencementandCompletion4.1Thecommencementdateoftheprojectis:_______(specifythestartdate).4.2Theexpectedcompletiondateoftheprojectis:_______(specifytheexpectedenddate).Article5:QualityStandards5.1Theworkshallbeperformedinaccordancewiththefollowingqualitystandards:_______(listtherelevantstandardsandspecifications).Article6:ConstructionDrawingsandDocuments6.1TheClientshallprovidetheContractorwiththenecessaryconstructiondrawingsanddocumentsby:_______(specifythedate).Article7:SupervisionandInspection7.1TheClientshallhavetherighttosuperviseandinspecttheworkatanytimeduringtheconstructionperiod.Article8:ChangesandVariations8.1Anychangestothescopeofworkorprojectspecificationsshallbeagreeduponinwritingbybothpartiesandmayresultinadjustmentstothecontractpriceandtimeline.Article9:DelaysandExtensionsofTime9.1TheContractorshallnotifytheClientimmediatelyofanycircumstancesthatmayresultinadelay.9.2TheClientmaygrantextensionsoftimeatitssolediscretion.Article10:SafetyandEnvironmentalProtection10.1TheContractorshallcomplywithallapplicablesafetyregulationsandenvironmentalprotectionlawsduringtheconstructionprocess.Article11:WarrantiesandRepresentations11.1Eachpartyrepresentsandwarrantsthatithasthefullright,power,andauthoritytoenterintothiscontractandtoperformitsobligations.Article12:Termination12.1Eitherpartymayterminatethiscontractintheeventofamaterialbreachbytheotherpartythatremainsuncuredafterwrittennotice.Article13:DisputeResolution13.1AnydisputesarisingoutoforinconnectionwiththiscontractshallberesolvedthrougharbitrationinaccordancewiththerulesofthearbitrationinstitutionspecifiedinthisArticle.Article14:ForceMajeure14.1Neitherpartyshallbeliableforanyfailureordelayinperformingitsobligationsduetoforcemajeureevents.Article15:AssignmentandSubcontracting15.1TheContractorshallnotassignorsubcontractitsrightsorobligationsunderthiscontractwithoutthepriorwrittenconsentoftheClient.Article16:Notices16.1Allnoticesunderthiscontractshallbeinwritingandshallbedeemedeffectiveuponreceipt.Article17:GoverningLaw17.1ThiscontractshallbegovernedbyandconstruedinaccordancewiththelawsofthejurisdictionspecifiedinthisArticle.Article18:EntireAgreement18.1Thiscontractconstitutestheentireagreementbetweenthepartiesandsupersedesallpriornegotiations,understandings,andagreements.甲方（蓋章）/Client(Seal):_______乙方（蓋章）/Contractor(Seal):_______法定代表人或授權(quán)代表簽字/LegalRepresentativeorAuthorizedSignatory:_______簽訂日期/DateofSigning:_______（注：以上為合同的前半部分，合同的后半部分將在下一個(gè)提問中繼續(xù)提供。）正文結(jié)束即停止回答。Article19:Insurance19.1TheContractorshallmaintainallrequiredinsurances,includingbutnotlimitedtoworkers'compensation,generalliability,andpropertydamageinsurance.Article20:LiquidatedDamages20.1Intheeventofadelayinthecompletionoftheprojectbeyondtheagreedtimeframe,theContractorshallpayliquidateddamagestotheClientasspecifiedinthisArticle.Article21:PerformanceBonds21.1TheContractormayberequiredtoprovideaperformancebondtosecureitsobligationsunderthecontract.Article22:SiteAccessandConditions22.1TheClientshallprovidetheContractorwithreasonableaccesstothesiteandensurethatthesiteconditionsaresuitableforthecommencementofwork.Article23:CompliancewithLaws23.1TheContractorshallcomplywithallapplicablelaws,regulations,andbylawsinperformingitsobligationsunderthiscontract.Article24:IntellectualPropertyRights24.1AnyintellectualpropertyrightscreatedorusedinthecourseoftheprojectshallbethepropertyoftheClient.Article25:Post-CompletionObligations25.1TheContractorshallberesponsibleforanydefectsoromissionsintheworkforaperiodspecifiedinthisArticleaftercompletion.Article26:RighttoSuspendWork26.1TheClientreservestherighttosuspendworkintheeventofabreachofcontractorothercircumstancesasspecifiedinthisArticle.Article27:CovenantNottoSue27.1TheContractorcovenantsnottosuetheClientforanymatterrelatedtotheperformanceofthiscontractexceptinthecaseofabonafidedispute.Article28:Third-PartyBeneficiaryClauses28.1Anythird-partybeneficiaryclauses,ifany,shallbeclearlystatedandincorporatedintothiscontract.AnnexA:ProjectSpecificationsandDrawingsAnnexB:PaymentScheduleandMilestoneDeliverablesAnnexC:InsuranceRequirementsandCertificatesAnnexD:PerformanceBondDetailsAnnexE:ListofApplicableLawsandRegulations一、附件列表/AnnexList:Theannexestothiscontractprovidedetailedprojectspecifications,drawings,paymentschedules,insurancerequirements,performancebonddetails,andalistofapplicablelawsandregulationsthatareintegraltotheexecutionofthecontract.二、違約行為及認(rèn)定/BreachofContractandDetermination:Breachofcontractincludes,butisnotlimitedto,failuretomeetdeadlines,non-compliancewithqualitystandards,andfailuretocomplywithlawsandregulations.Thedeterminationofabreachissubjecttoverificationofthefactsandmayinvolvethird-partyi